| More |
Deliverable Number
|
Commodity/Service Type
|
Major Deliverable
|
Method of Payment
|
|
|
|
Inspection
|
Task 4:Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; U...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 4:Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12. Allowable travel reimbursement for 2021-2022 training. Total task not to exceed $136,585.00
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 1: The Contractor shall complete the following services in accordance with the requirements in ...
|
Fixed Price - Lump Sum
|
| Major Deliverable: Task 1: The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 914 : - Conduct routine compliance inspections at the199 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Counties set in the Task Assignment.
Compensation will only occur for routine annual compliance inspections conducted at the facilities. Routine $510.40, UST System Install $1,140.68, UST Piping Install $380.23, Component Install $190.11, UST System Closure $836.50, UST Piping Closure $418.25, Component Closure $209.12, AST System Install $570.34, AST Piping Install $190.11, AST Piping Closure $190.11, AST System Closure $380.23, Compliant $190.11,Discharge $190.11 Enforcement $190.11, Non-Compliance $190.11, Compliance Assistance Re-inspect $190.11. The Department reserves the right to retain 10% on the Compliance Routine Inspection (CRI) as specified in paragraph 21 reimbursement criteria for the amount retained. CO1: "Amount increase per Routine Inspection from $510.40 to $515.50.
A net increase of $5.10 per Routine Inspection.
The increase will become effective September 1, 2017. All inspections conducted through August 31, 2017, will be paid at the rate of $510.40."
CO2: Decrease in task amount (-5,000.00).
|
| Deliverable Price: $125,282.32 |
| Non Price Justification: |
| Performance Metrics: "The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment:(1) After four (4) months, thirty-three percent (33%) of inspections shall be completed.
(2) After eight (8) months, sixty-six (66%) of inspections shall be completed.
(3) After (12) months, one hundred percent (100%) of inspections shall be completed.
FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
"
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: Attachment B |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 2: Task 2 : The Contractor shall complete the following services in accordance with the requir...
|
Fixed Price - Lump Sum
|
| Major Deliverable: Task 2: Task 2 : The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 914 : - Conduct routine compliance inspections at the199 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Counties set in the Task Assignment.
Compensation will only occur for routine annual compliance inspections conducted at the facilities explicitly identified in Exhibit #1 (provided electronically). Routine $545.00, UST System Install $1,425.85, UST System Closure $920.15, AST System Install $712.93, AST System Closure $418.25, Compliance Assistance- Component $209.12, Compliance Assistance- Reinspection $209.12, Complaint $209.12, Discharge $209.12, and Staff Training Travel $400.00.
CO1: Updated scope of work
CO2: Revising sentence in current task assignment from reading : "Inspection staff to attend annual meeting Spring 2019 at a rate of $400 per staff member.
To read: "Inspection staff to attend annual meeting Spring 2019."
|
| Deliverable Price: $122,255.00 |
| Non Price Justification: |
| Performance Metrics: "The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment:(1) After four (4) months, thirty-three percent (33%) of inspections shall be completed.
(2) After eight (8) months, sixty-six (66%) of inspections shall be completed.
(3) After (12) months, one hundred percent (100%) of inspections shall be completed.
FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
"
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: Attachment B |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 3 : The Contractor shall complete the following services in accordance with the requirements in...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 3 : The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 914: - Conduct routine compliance inspections at the 199 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Leon and specified counties.
Compensation will only occur for routine annual compliance inspections conducted at the facilities explicitly identified in Exhibit #1 (provided electronically). Routine $515.50, UST System Install $1,425.85, UST System Install - tank count greater than 10 - $2,100, UST System Closure $920.15, UST System Closure-Tank count greater than 10 $1,350, AST System Install $712.93, AST System Closure $418.25, Compliance Assistance-Component $209.12, Compliance Assistance- Re inspection $209.12, Complaint $209.12, Discharge $209.12. Task not to exceed $136,585.00. CO1: Time extension. |
| Deliverable Price: $0.00 |
| Non Price Justification: Rate Agreement |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: CO1 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 5: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 5: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Allowable travel reimbursement for 2021-2022 training. Total task not to exceed $132,041.00 |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment. |
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed |
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 6: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $545.00; ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 6: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $545.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $137,911.00.
CO1 - Completion Date extension, from 5/31/23 to 6/30/23
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 7:
Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $785.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 7:
Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $785.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. TACO 1 - Completion Date extension, from 5/31/23 to 6/30/23. Total task not to exceed $145,679.54. |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T7 CO1 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 8: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 8: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $189,724.54. TACO 1- Extended Date of Completion date to June 30, 2025.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: T8 CO1 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 9: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 9: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $189,190.50.
CO2-Completion date extension of RCIs from 5/31/26 to 6/30/26. Total Task not to exceed $206,690.50.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: T9 CO2 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 10:
Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 10:
Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Attend 2006 - 2007 training meeting. Submit travel reimbursement forms, supporting receipts and agenda for 2026-2027 training. Total task not to exceed $206,475.50.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|