| More |
Deliverable Number
|
Commodity/Service Type
|
Major Deliverable
|
Method of Payment
|
|
|
|
Inspection
|
Task 4: The Contractor shall complete the following services in accordance with the requirements in ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 4: The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 928: - Conduct routine compliance inspections at the 58 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Sumter County.
Compensation will only occur for routine annual compliance inspections conducted at the facilities explicitly identified in Exhibit #1 (provided electronically). Routine $545.00, UST System Install $1,425.85, UST System Closure $920.15, AST System Install $712.93, AST System Closure $418.25, Compliance Assistance- Component $209.12, Compliance Assistance- Reinspection $209.12, Complaint $209.12, Discharge $209.12, and Staff Training Travel $400.00. The Department shall pay the Contractor on a cost reimbursement plus fixed fee basis not to exceed $41,610.00.
CO1: Updated Scope of Work. CO2: Increase in task amount $7,000.00. CO3: Revising sentence in current task assignment from reading : Inspection staff to attend annual meeting Spring 2019 at a rate of $400 per staff member. To read: Inspection staff to attend annual meeting Spring 2019. |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment:(1) After four (4) months, thirty-three percent (33%) of inspections shall be completed.
(2) After eight (8) months, sixty-six (66%) of inspections shall be completed.
(3) After (12) months, one hundred percent (100%) of inspections shall be completed.
FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: GC928T4CO2 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 1 : The Contractor shall complete the following services in accordance with the requirements in...
|
Fixed Price - Lump Sum
|
| Major Deliverable: Task 1 : The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 928: - Conduct routine compliance inspections at the 147 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Citrus, and HernandoCounties.
Compensation will only occur for routine annual compliance inspections conducted at the facilities. Routine $515.50, UST System Install $1,140.68, UST Piping Install $380.23, Component Install $190.11, UST System Closure $836.50, UST Piping Closure $418.25, Component Closure $209.12, AST System Install $570.34, AST Piping Install $190.11, AST Piping Closure $190.11, AST System Closure $380.23, Compliant $190.11,Discharge $190.11 Enforcement $190.11, compliance assistance re-inspect $190.11, Non-Compliance $190.11, Compliance Assistance Reinspect $190.11. The Department reserves the right to retain 10% on the Compliance Routine Inspection (CRI) as specified in paragraph 21 reimbursement criteria for the amount retained. CO1: Increase in funds ($952.12). CO2:CO 2 decrease in task amount $ $10,000.00
|
| Deliverable Price: $86,238.70 |
| Non Price Justification: |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment:(1) After four (4) months, thirty-three percent (33%) of inspections shall be completed.(2) After eight (8) months, sixty-six (66%) of inspections shall be completed.(3) After (12) months, one hundred percent (100%) of inspections shall be completed.
FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: Attachment B |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 5: The Contractor shall complete the following services in accordance with the requirements in ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 5: The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 928: - Conduct routine compliance inspections at the 147 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Sumter County.
Compensation will only occur for routine annual compliance inspections conducted at the facilities explicitly identified in Exhibit #1 (provided electronically). Routine $515.50, UST System Install $1,425.85, UST System Closure $920.15, UST System Closure-Tank count greater than 10 $1,350, AST System Install $712.93, AST System Closure $418.25, Compliance Assistance-Component $209.12, Compliance Assistance- Re inspection $209.12, Complaint $209.12, Discharge $209.12 ; CO 1: Increase task amount for Travel Allotment for $350; Increase amount for Variable Inspections for $1,200. CO2: increase amount for Variable Compliance Inspections for $1,835.Total Task not to exceed $97,164.00. |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 2 : The Contractor shall complete the following services in accordance with the requirements in...
|
Fixed Price - Lump Sum
|
| Major Deliverable: Task 2 : The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 928: - Conduct routine compliance inspections at the 58 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Sumter County.
Compensation will only occur for routine annual compliance inspections conducted at the facilities explicitly identified in Exhibit #1 (provided electronically)." Routine $515.50, UST System Install $1,140.68, UST Piping Install $380.23, Component Install $190.11, UST System Closure $836.50, UST Piping Closure $418.25, Component Closure $209.12, AST System Install $570.34, AST Piping Install $190.11, AST Piping Closure $190.11, AST System Closure $380.23, Compliant $190.11,Discharge $190.11 Enforcement $190.11, compliance assistance re-inspect $190.11, Non-Compliance $190.11. The Department reserves the right to retain 10% on the Compliance Routine Inspection (CRI) as specified in paragraph 21 reimbursement criteria for the amount retained.
CO1: Increase in funds ($375.67).
CO3: Revising sentence in current task assignment from reading : ‘Inspection staff to attend annual meeting Spring 2019 at a rate of $400 per staff member.’
To read: Inspection staff to attend annual meeting Spring 2019."
|
| Deliverable Price: $37,971.73 |
| Non Price Justification: |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment:(1) After four (4) months, thirty-three percent (33%) of inspections shall be completed.(2) After eight (8) months, sixty-six (66%) of inspections shall be completed.(3) After (12) months, one hundred percent (100%) of inspections shall be completed.
FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: Attachment B |
| Deliverable Number: |
|
|
|
|
Inspection
|
"Task 3 : The Contractor shall complete the following services in accordance with the requirements i...
|
Fixed Price - Lump Sum
|
| Major Deliverable: "Task 3 : The Contractor shall complete the following services in accordance with the requirements in DEP Contract No. GC 928: - Conduct routine compliance inspections at the 147 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Citrus, and HernandoCounties.
Compensation will only occur for routine annual compliance inspections conducted at the facilities explicitly identified in Exhibit #1 (provided electronically)." Routine $545.00, UST System Install $1,425.85, UST System Closure $920.15, AST System Install $712.93, AST System Closure $418.25, Compliance Assistance-Component $209.12, Compliance Assistance- Re inspection $209.12, Complaint $209.12, Discharge $209.12, Staff Training Travel $400.00.
CO1: Updated scope of work. CO2: Increase in task amount of $12,000.00; CO4: Increase in funds for variable inspections for $100; |
| Deliverable Price: $99,015.00 |
| Non Price Justification: |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment:(1) After four (4) months, thirty-three percent (33%) of inspections shall be completed.
(2) After eight (8) months, sixty-six (66%) of inspections shall be completed.
(3) After (12) months, one hundred percent (100%) of inspections shall be completed.
FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 6: The Contractor shall complete the following services: Conduct routine compliance inspections...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 6: The Contractor shall complete the following services: Conduct routine compliance inspections at the 58 facilities identified in Exhibit #1 (provided electronically). Perform inspections for all reported complaints, discharges, installations and closures involving storage tank systems within Sumter County. Compensation will only occur for routine annual compliance inspections conducted at the facilities explicitly identified in Exhibit #1 (provided electronically). Routine $515.50, UST System Install $1,425.85, UST System Install (tank count greater than 10) $2,100, UST System Closure $920.15, UST System Closure-Tank count greater than 10 $1,350, AST System Install $712.93, AST System Closure $418.25, Compliance Assistance-Component $209.12, Compliance Assistance- Reinspection $209.12, Complaint $209.12, Discharge $209.12. Total task not to exceed $39,899.00. CO1: Increase amount for Variable Inspections for $1,700. Total Task not to exceed $41,599.00. |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T6CO1 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 8: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; ...
|
Cost Reimbursement
|
| Major Deliverable: Task 8: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12. Total task not to exceed $41,599.00. |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: T8 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 7: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 7: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12. Total task not to exceed $97,514.00.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: T7 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 9: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; ...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 9: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $97,742.00 |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment |
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed |
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|
|
|
|
Inspection
|
T10: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; UST...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: T10: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $515.50; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.1, Ethanol Inspections $209.12. Total task not to exceed $41,462.00 |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignm |
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed |
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 11: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $545.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 11: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $545.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $102,078.00.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 12: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $545.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 12: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $545.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.1, Ethanol Inspections $209.12. Total task not to exceed $43,173.00.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignm
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed
|
| Source Documentation Page Reference: Attachment C |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 20: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 20: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.1, Ethanol Inspections $209.12. Attend 2026-2027 Training meeting. Submit travel reimbursement forms, supporting receipts and travel agenda for 2026-2027 training. Total task not to exceed $54,827.75.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T20 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 19: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 19: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Attend 2026-2027 training meeting. Submit travel reimbursement forms, supporting receipts and travel agenda for 2026-2027 training. Total task not to exceed $106,281.36.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T19 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 14: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $785.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 14: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $785.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.1, Ethanol Inspections $209.12. Total task not to exceed $44,220.66. TACO 1 - Increase of $4,300 for Variable inspections fund. Total Task Amount not to exceed $48,520.66. TACO 2 - Increase of $2,200 for Variable inspections fund. Total Task Amount not to exceed $50,720.66. TACO 3: Time completion extension from 5/31/24 to 6/30/24.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: CO3 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 13: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $785.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 13: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $785.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $104,356.41. TACO 1- Decrease of $2,300 from Variable Inspectons fund. Total Task Amount not to exceed $102,056.41. TACO 2- Increase of $7,000 from Variable Inspections fund. Total Task Amount not to exceed $109,056.41.
CO1: Cost decrease. CO2: Cost increase. CO3: Time completion extension from 5/31/24 to 6/30/24. |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T13 CO3 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Amendment 3: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Amendment 3: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $103,698.36. Amendment 3- Increase in funds for $179,553.79. Total contract amount not to exceed $1,447,717.79.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: A3 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 16: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 16: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.1, Ethanol Inspections $209.12. Total task not to exceed $51,640.66. TACO 1- Invoice 4 reduce to 26% or 13 RCIs. Total Task should not exceed $51,640.66.
CO1: Due to storm impacts (Milton), for invoice 4, GC928-16 Citrus (Sumter) County, shall complete (26%) or 13 Routine Compliance Inspections.
CO2: Extension of Time Completion to June 30, 2025. Total Task should not exceed $51,640.66. |
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T16 CO2 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 15: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 15: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $102,241.41.TACO 1-Performance Measures reduced to 23% for invoice 4. TACO 2-Increase in funds for Variable Inspection for $5,750. Total Task not to exceed $107,191.41.
CO1: Performance Measures reduced to 23% for invoice 4. CO2:Increase in funds for Variable Inspection for $5,750.
CO3:Extension of Time Completion to June 30, 2025. Total Task not to exceed $107,191.41.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment. |
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed. |
| Source Documentation Page Reference: T15 CO3 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 18: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00;...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 18: Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $47,097.75
CO1: Performance Measures reduce invoice 8 percentage from 66% to 55% or 64 RCIs.
CO2: Completion date extension of RCIs from 5/31/26 to 6/30/26. Total Task not to exceed $47,097.75.
CO3: Increase in funding for Variable Inspections for $8,200. Total Task not to exceed $55.297.75.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T18 CO3 |
| Deliverable Number: |
|
|
|
|
Inspection
|
Task 17:
Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00...
|
Cost Reimbursement Plus Fixed Fee(s), including Fixed Price Components
|
| Major Deliverable: Task 17:
Routine Inspections at the facilities identified in Exhibit #1. Routine Inspection $800.00; UST System Install $1,425.85; UST System Install - tank count greater than 10 - $2,100; UST System Closure $920.15; UST System Closure - tank count greater than 10 - $1350; AST System Install $712.93; AST System Closure $418.25; Compliance Assistance - Component $209.12; Compliance Assistance - Reinspection $209.12; Complaint $209.12; Discharge $209.12, Ethanol Inspections $209.12. Total task not to exceed $103,698.36.
CO1- Performance Measures reduce invoice 8 percentage from 66% to 55% or 64 RCIs.
CO2- Performance Measures reduce invoice 8 percentage from 66% to 49% or 57 RCIs.
CO3: Completion date extension of RCIs from 5/31/26 to 6/30/26.
CO4-Increase in funding for Variable Inspections for $2,700. Total Task not to exceed $106,398.36.
|
| Deliverable Price: $0.00 |
| Non Price Justification: Price cannot be determined until the work has been completed |
| Performance Metrics: The Contractor must perform all Enforcement Actions in accordance with Guidance Document F (Level of Effort). Following the effective date of Each Task Assignment, the CONTRACTOR shall complete the following percentage of the required routine compliance inspections unless otherwise indicated in the Task Assignment: (1) After four (4) months, thirty-three percent (33%) of inspections shall be completed. (2) After eight (8) months, sixty-six (66%) of inspections shall be completed. (3) After (12) months, one hundred percent (100%) of inspections shall be completed. FDEP will adjust the funding level of this task assignment as needed to complete the scope of services described within this Task Assignment.
|
| Financial Consequences: If the CONTRACTOR fails to perform in a timely and proper manner, in the judgment of the DEP, the DEP may terminate this Contract by thirty (30) days written notice, specifying the effective time/date of termination. In this event, the CONTRACTOR shall be compensated for any work satisfactorily completed.
|
| Source Documentation Page Reference: T17 CO4 |
| Deliverable Number: |
|